Global IT Chat Now
1 (877) 822-5565

Web Development Terms of Service

GLOBAL IT, Internet T1, Global IT Web Design and Terms of Service

1. Introduction
This page contains Global IT Communications, Inc. (the "company", "us", "we", or "our") Web Development Terms of Service. Global IT expects its clients (the “customer,” “user,” “you,” or “your”) to carefully read and understand this document. By doing business with Global IT, you are subject to the following terms and conditions. 

2. Changes to this Agreement
Global IT reserves the right to modify these terms at any time, or against any customer it believes is abusing this agreement. Any such revision or change will be binding and effective immediately after posting of the revised Terms of Service on our website.  You agree to periodically review our Terms of Service, including the current version of our Terms of Service. Our Web Development Terms of Service agreement is made available at:  It is your obligation to review our Terms of Service for any such revisions. 

3. Quotes & Contracts
Quotes and promotional rates provided to prospects will be honored for up to 15 days. A new quote will then be provided upon request. Contract that have been written, but not signed by the client will only be accepted within 15 days of the delivery date. A new contract may be drawn up upon request. 

4.  Charges & Fees
All new web design projects require an initial 50% deposit that will be due at contract signing. The remaining 50% balance will be due upon acceptance of the completed web development project before it is released to the client or published to the internet. Clients outside the United States are required to pay in full for their web design project. This is non-negotiable. 
Any check payments that do not clear will be charged a $35 fee. Global IT Communications, Inc. retains the right to hold all graphics, and project development with the exception of content and graphics provided by the client, until payment is received for such items.
Global IT Communications, Inc. accepts payments via Cash, Check, ACH, PayPal and all major Credit Cards. Your project will not be released to you or uploaded until full payment is received. Global IT Communications, Inc. will not negotiate chargebacks with any person or company.

5. Hours of Operation
Our business hours are Monday-Friday from 8am-5pm PST.  If you require maintenance after the posted hours, such as on weekends or holidays, you will be charged our base rate of $95 per hour with an additional charge of $45 per hour for after hour’s assistance.

6. Domain Transfer / Domain Name Server Changes
In order to host the client's website upon its publication, it may be necessary to perform what is known as a DNS (Domain Name Server) change to the client's domain name. This change will make it possible for visitors to view the new website whenever they visit the domain name owned by the client. We will provide the necessary DNS and IP modifications to a single domain name owned by the client as long as the changes don't exceed one hour (1 hr) of our developer's time. In order to perform the DNS change, we request that the client sends us a username and password to the control panel used to manage the domain name. If this is not possible, we may be able to contact the registrar (domain registration company) on behalf of the client and work with them to perform the necessary modifications. We reserve the right to charge the client by the hour to assist in transferring their domain name or perform the DNS modifications if we believe the amount of time needed to perform the changes could be excessive. The hourly rate applied will be the same as our standard design rate of $75.00 USD. 

7. Requesting Additional Pages or Content Changes
With new websites, the client is expected to provide Global IT with a list of pages he/she wishes to build for the website. In addition, we assume that any content to be built will be presented within the first week of initial web design purchase or before the TR is complete. With new websites or redesigns, requests for new pages or additional content after the completion of the contract will not be accepted. We reserve the right to bill the client separately for any requests that are not declared upon completion of the contract. 

8. Web Site Design Credit
All Global IT custom web design clients will have "Powered by Global IT" link on their website in the footer of every page. This is non-negotiable. By hiring us to work on your website you are agreeing to this, and that you understand that this link may NOT be removed without our consent. At our sole discretion, we may agree to accept a fee of $250 USD to allow this link to be permanently removed. Should you have a new layout designed for your site by a company other than Global IT, you may remove the credit from your website.

9. Copyright & Ownership
Upon completion of the project, Global IT transfers all rights and ownership of custom designs and programming written by Global IT to the client. Software and third party graphics or programs are not transferred to the client and remain under copyright of their respective owners.  Global IT reserves the right to resell custom designed web sites that remain unpaid by the original client, unaccepted mockups or other graphics created by our company but not in legal use by the client.  Global IT reserves the right to display websites and graphics that have been designed by our company, and in any marketing material to aid as examples of our work. 

10. Development & Delivery
Global IT understands the importance of completing projects in a timely manner. If the client does not supply Global IT with complete text, graphic content and other requested materials for the website within 30 days of initial web design purchase, the work order becomes void and all deposits and other payments paid by the client are forfeited. The client may request a Project Extension in writing to Global IT for an additional fee. All extension fees are due upon agreement of the extension between Global IT and the client.  If the contract has been completed by Global IT and the client takes longer than 45 days to approve the work, the project can be canceled without prior notice and no refund will be issued.

11. Development Requests
Unless the client is hosting his website with Global IT, we will consider our work on the website finished once it has been published or approved by the client. Additional development or assistance after the website is deemed "complete" will be billed by the hour. The hourly rate will be determined at the time of the request and may differ from the initial web development purchase price. If the client is hosting his website with Global IT, limited support will be provided on a monthly basis according to our Hosting Terms of Service. Clients may review the Managed Hosting Terms of Service at:   

12. Non-Communication
If we are unable to communicate with a client on a project for a duration of at least 45 days by phone or email during the design and development process, the project will be canceled without prior notice and no refund will be issued. 

13. Delays in Project Completion
Global IT cannot be held liable for the failure to complete a project within a pre-determined time frame or by a specified deadline. We cannot be held liable for any predicted estimate of profits in which a client would have gained if their site was functioning or had been published (made publicly available online) by a certain date.  Project due dates provided to the client by Global IT, are estimates based on the number of currently open projects. We cannot guarantee that a project will be finished by a specified date. All due dates and deadlines are not final and may be revised if needed.  Projects may fall behind schedule due to circumstances beyond our control, such as an unexpected increase in the workload provided to us by other clients. Projects may also be delayed if they require more design time than initially anticipated by our web designer or project manager. 

14. Hold Harmless
You agree to protect, defend, indemnify and hold us harmless from and against any and all claims, causes of action, liabilities, judgments, penalties, losses, costs, damages and expenses (including attorneys' fees and all related costs and expenses of litigation at arbitration, or at trial or on appeal, if any, whether or not litigation or arbitration is instituted) suffered or incurred by us, including, without limitation, any claim for personal injury, property damage, or loss of profit arising from: (i) these Terms; (ii) the Services provided to you by us; (iii) your use of the Services including without limitation any copyright infringement claims that could arise from storing your website files on our web server; (iv) the failure of our company to provide any services on time or as expected; (v) loss, damage, or destruction of your website or email messages by any cause whatsoever whether or not attributable to our negligence or intentional act; (vi) any violation by you of any federal, state or local laws, statutes, rules or regulations; and (vii) for the consequences of any attempts of third parties to serve you with legal process through the Services or our facility. For purposes of these Terms, the indemnified parties shall include Global IT and its owners, affiliates, subsidiaries, members, successors, assigns, representatives, officers, directors, agents, attorneys and employees. 

15. Refusal of Service
Global IT reserves the right to decline to do business with any client, at any time, and for any reason. 

16. Termination of Design Service
We reserve the right to discontinue the design of your website and terminate our mutual business relationship at any stage in the design process and for any of the following reasons:  (1) We believe your behavior or communication towards our staff (employees, owners and affiliates) or other customers is offensive, abusive, violent, threatening or disruptive in any way.  (2) Our employees, representatives, support staff and or other members of Global IT believe they are unable to communicate with you effectively. This may be due to an inability to reach you over a prolonged period of time or in the case that we are not able to come to an agreement about certain aspects of the design of your website. If we decide to discontinue the design of your website, you will be provided with a partial refund, calculated based on the time we spent working on your website and communicating with you in regards to the project. The amount of the refund provided will be decided at our sole discretion.

17. Third Party Vendors
Third party vendors may have separate terms of service agreements. Global IT cannot be held liable for disputes with third party vendors. Global IT cannot be held responsible for lack of functionality or any other aspect of third party services.

18. Acceptance
Please note that by submitting your down payment for our design service you are agreeing to all of our terms of service as written here. Global IT reserves the right to change or update these terms at any time without prior notice. 

19. Miscellaneous
This agreement shall be governed by and construed in accordance with the laws of the state of California.  If any provision of this agreement shall be unlawful, void, or for any reason unenforceable, then that provision shall be deemed severable from this agreement and shall not affect the validity and enforceability of any remaining provisions.  Revised and effective: October 1st, 2016.

Featured Customers

arin internap tech support paramount tech support calvin klein global it tech support Mr C Hotels fiber internet Malibu Beach Inn fiber internet four points sheraton global it tech support American Express Allied Commercial Real Estate global it tech support Keller Williams Centric Parts arctic glacier union ice collard rose global it tech support howard industries tech support foxconn fiber internet gigabyte technology tech support friendly hills country club collectors universe Vendor Cisco Vendor Juniper Networks level3